Search Legislation

British Railways (No. 2) Act 1992

 Help about what version

What Version

  • Latest available (Revised)
  • Original (As enacted)

More Resources

Status:

This is the original version (as it was originally enacted). This item of legislation is currently only available in its original format.

Part IVLand

Purchase of land, etc.

26Purchase of land

(1)The Board may purchase compulsorily and use such of the land delineated on the deposited plans and described in the deposited book of reference as they require for the purpose of the works or for any purpose connected with or ancillary to their undertaking.

(2)Without prejudice to the generality of subsection (1) above, the Board may purchase compulsorily and use for the purposes specified in column (3) of Part I of Schedule 2 to this Act all or any of the land referred to in columns (1) and (2) of that

(3)The Board may enter upon, use and appropriate so much of the subsoil and undersurface of, or airspace over, any public street, road, footway or place delineated on the deposited plans and described in the deposited book of reference as shall be necessary for the purposes of subsection (1) above without being required to purchase the same or any easement or other right therein, thereunder or thereover or to make any payment therefor.

(4)The Board shall not exercise the powers of this section or section 27 (Purchase of rights over land) of this Act in relation to any land to which section 29 (Temporary use of land) of this Act applies.

27Purchase of rights over land

(1)In this section references to the purchase by the Board of new rights are references to the purchase of rights to be created in favour of the Board.

(2)Subject to the provisions of this Act, the Board may for the purpose of constructing, maintaining, protecting, altering, renewing and using the works, or for the purpose of obtaining access to the works or for the purpose of doing any other thing necessary in connection with the works, purchase compulsorily such new rights as they require in or over any of the land delineated on the deposited plans and described in the deposited book of reference instead of purchasing that land under section 26 (Purchase of land) of this Act.

(3)The Act of 1965, as applied by this Act, shall have effect with the modifications necessary to make it apply to the compulsory purchase of new rights under subsection (2) above as it applies to the compulsory purchase of land so that, in appropriate contexts, references in the Act of 1965 to land are read as referring, or as including references, to the new rights or to land in or over which the new rights are, or are to be, exercisable, according to the requirements of the particular context.

(4)Without prejudice to the generality of subsection (3) above, in relation to the purchase of new rights under subsection (2) above—

(a)Part I of the Act of 1965 shall have effect with the modifications specified in Schedule 3 to this Act; and

(b)the enactments relating to compensation for the compulsory purchase of land shall apply with the necessary modifications as they apply to such compensation.

28Purchase of specific new rights over land

(1)Section 27 (Purchase of rights over land) of this Act shall have effect for enabling the Board to purchase such further new rights as they require under this section.

(2)The Board may, in addition to such new rights as they may purchase under the said section 27 of this Act, purchase such new rights as they require in or over any of the lands shown on the deposited plans within the lines marked “Limit of easement to be acquired” or “Limit of land required for temporary access” and specified in Part II of Schedule 2 to this Act for the provision of means of access to the highways there mentioned.

29Temporary use of land

The provisions set out in Part III of Schedule 2 to this Act shall have effect with respect to the temporary use of land by the Board for working sites.

General lands provisions

30Purchase of part of certain properties

(1)Where a copy of this section is endorsed on, or annexed to, a notice to treat served under the Act of 1965, as applied by this Act, the following provisions of this section shall apply to the land subject to the notice instead of section 8 (1) of that Act.

(2)Where the land subject to the notice is part only of a house, building or factory, or part only of land consisting of a house, together with any park or garden belonging thereto, if the person on whom the notice is served, within 21 days after the day on which the notice is served on him, serves on the Board a counter-notice objecting to the sale of the part and stating that he is willing and able to sell the whole (in this section referred to as “the land subject to the counter-notice”), the question whether he shall be required to sell the part shall, unless the Board agree to take the land subject to the counter-notice, be referred to the tribunal.

(3)If the said person does not serve such a counter-notice as aforesaid within 21 days after the day on which the notice to treat is served on him, or if, on such a reference to the tribunal, the tribunal determine that the part subject to the notice to treat can be taken without material detriment to the remainder of the land subject to the counter-notice or, in the case of part of land consisting of a house, together with a park or garden belonging thereto, without such detriment and without seriously affecting the amenity and convenience of the house, the said person shall be required to sell the part.

(4)If, on such a reference to the tribunal, the tribunal determine that part only of the land subject to the notice to treat can be taken without material detriment to the remainder of the land subject to the counter-notice or, as the case may be, without such detriment and without seriously affecting the amenity and convenience of the house, the notice to treat shall be deemed to be a notice to treat for that part.

(5)If, on such a reference to the tribunal, the tribunal determine that the land subject to the notice to treat cannot be taken without material detriment to the remainder of the land subject to the counter-notice but that the material detriment is confined to a part of the land subject to the counter-notice, the notice to treat shall be deemed to be a notice to treat for the land to which the material detriment is confined in addition to the land already subject to the notice, whether or not the additional land is land which the Board are authorised to purchase compulsorily under this Act.

(6)If the Board agree to take the land subject to the counter-notice, or if the tribunal determine that—

(a)none of the land subject to the notice to treat can be taken without material detriment to the remainder of the land subject to the counter-notice or, as the case may be, without such detriment and without seriously affecting the amenity and convenience of the house; and

(b)the material detriment is not confined to a part of the land subject to the counter-notice;

the notice to treat shall be deemed to be a notice to treat for the land subject to the counter-notice whether or not the whole of the land is land which the Board are authorised to purchase compulsorily under this Act.

(7)In any case where, by virtue of a determination by the tribunal under subsection (4), (5) or (6) above a notice to treat is deemed to be a notice to treat for part of the land specified in the notice or for more land than is specified in the notice, the Board may, within six weeks after the tribunal make their determination, withdraw the notice to treat and, if they do so, shall pay to the said person compensation for any loss or expense occasioned to him by the giving and withdrawal of the notice, to be determined in case of dispute by the tribunal:

Provided that the determination of the tribunal shall not be deemed to be made so long as—

(a)the time for requiring the tribunal to state a case with respect thereto has not expired and any proceedings on the points raised by a case so stated have not been concluded; or

(b)any proceedings on appeal from any decision on the points raised by a case so stated have not been concluded.

(8)(a)Where a person is required under this section to sell part only of a house, building or factory, or land consisting of a house, together with any park or garden belonging thereto, the Board shall pay him compensation for any loss sustained by him due to the severance of that part in addition to the value of his interest therein.

(b)Any dispute as to a person’s entitlement to compensation under this section or as to the amount of compensation shall be determined by the tribunal.

31Disregard of recent improvements and interests

In determining a question with respect to compensation claimed in consequence of the compulsory purchase of land under this Act, the tribunal shall not take into account—

(a)any interest in land; or

(b)any enhancement of the value of any interest in land by reason of any building erected, works executed or improvement or alteration made (whether on the land purchased or on any other land with which the claimant is, or was at the time of the erection, executing or making of the building, works, improvement or alteration, directly or indirectly concerned):

if the tribunal are satisfied that the creation of the interest, the erection of the building, the execution of the works or the making of the improvement or alteration, as the case may be, was not reasonably necessary and was undertaken with a view to obtaining compensation or increased compensation.

32Extinction or suspension of private rights of way

(1)All private rights of way over any land which may be purchased compulsorily under this Act shall be extinguished on the purchase of the land, whether compulsorily or by agreement, or on the entry on the land under section 11(1) of the Act of 1965 as applied by this Act, whichever is sooner.

(2)All private rights of way over any land of which the Board may take temporary possession under this Act shall be suspended and unenforceable against the Board for so long as the Board shall remain in lawful possession thereof.

(3)Any person who suffers loss by the extinguishment or suspension of any right under this section shall be entitled to be paid by the Board compensation, to be determined in case of dispute by the tribunal.

33Correction of errors in deposited plans and book of reference

(1)If the deposited plans or the deposited book of reference are inaccurate in their description of any land, or in their statement or description of the ownership or occupation of any land, the Board after giving not less than 10 days' notice to the owner, lessee and occupier of the land in question may apply to two justices having jurisdiction in the place where the land is situated for the correction thereof.

(2)If on any such application it appears to the justices that the misstatement or wrong description arose from mistake, the justices shall certify the fact accordingly and shall in their certificate state in what respect any matter is misstated or wrongly described.

(3)The certificate shall be deposited in the office of the Clerk of the Parliaments, and a copy thereof in the Private Bill Office of the House of Commons, and with the proper officer or chairman of a local authority with whom a copy of the deposited plans has been deposited in accordance with the Standing Orders of the Houses of Parliament, or who has the custody of any such copy so deposited; and thereupon the deposited plans and the deposited book of reference shall be deemed to be corrected according to the certificate, and it shall be lawful for the Board to take the land and execute the works in accordance with the certificate.

(4)A person with whom a copy of the certificate is deposited under this section shall keep it with the other documents to which it relates.

34Cellars under streets not referenced

Nothing in this Act shall authorise the Board to purchase compulsorily or use (except by agreement) any cellar or vault in or under any street belonging to or connected with any building unless the cellar or vault or the building with which it is connected is described in the deposited book of reference.

35Set-off for enhancement in value of retained land

(1)In this section “relevant land” means any land purchased, or any land in or over which any new rights are purchased, by the Board for the purposes of the works.

(2)In assessing the compensation payable to any person on the purchase by the Board from him of any relevant land or any rights therein, the tribunal shall—

(a)have regard to the extent to which the land or the remaining contiguous lands belonging to the same person may be benefited by any of the works; and

(b)set off against the value of the relevant land any increase in value of the remaining contiguous lands belonging to the same person which will accrue to him by reason of the construction of any of the works.

(3)The [1961 c. 33.] Land Compensation Act 1961 shall have effect subject to the provisions of this section.

36Time for purchase of land and rights over land

The powers of the Board for the compulsory purchase of land and rights in or over land under this Act shall cease on 31st December 1995.

Extension of time

37Extension of time

The period now limited for the exercise by the Board of the powers of section 30 (Temporary possession of lands and access at Basingstoke and Wandsworth) of the [1986 c. iii.] British Railways Act 1986 in their application to the temporary possession of lands and access in the London borough of Wandsworth is hereby extended until 31st December 1995.

Back to top

Options/Help

Print Options

Close

Legislation is available in different versions:

Latest Available (revised):The latest available updated version of the legislation incorporating changes made by subsequent legislation and applied by our editorial team. Changes we have not yet applied to the text, can be found in the ‘Changes to Legislation’ area.

Original (As Enacted or Made): The original version of the legislation as it stood when it was enacted or made. No changes have been applied to the text.

Close

Opening Options

Different options to open legislation in order to view more content on screen at once

Close

More Resources

Access essential accompanying documents and information for this legislation item from this tab. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as enacted version that was used for the print copy
  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • correction slips
  • links to related legislation and further information resources