Search Legislation

The Network Rail (Ipswich Chord) Order 2012

 Help about what version

What Version

  • Latest available (Revised)
  • Original (As made)

Status:

This is the original version (as it was originally made). This item of legislation is currently only available in its original format.

Article 30

SCHEDULE 7PROTECTIVE PROVISIONS

PART 1FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS

1.  For the protection of the undertakers referred to in this Part of this Schedule the following provisions, unless otherwise agreed in writing between Network Rail and the undertaker concerned, have effect.

2.  In this Part of this Schedule—

“alternative apparatus” means alternative apparatus adequate to enable the undertaker in question to fulfil its statutory functions in a manner not less efficient than previously;

“apparatus” means—

(a)

in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989(1)), belonging to or maintained by that undertaker;

(b)

in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply;

(c)

in the case of a water undertaker, mains, pipes or other apparatus belonging to or maintained by that undertaker for the purposes of water supply; and

(d)

in the case of a sewerage undertaker—

(i)

any drain or works vested in the undertaker under the Water Industry Act 1991(2); and

(ii)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act,

and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,

and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

“functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or upon land; and

“undertaker” means—

(e)

any licence holder within the meaning of Part 1 of the Electricity Act 1989;

(f)

a gas transporter within the meaning of Part 1 of the Gas Act 1986(3);

(g)

a water undertaker within the meaning of the Water Industry Act 1991; and

(h)

a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,

for the area of the authorised development, and in relation to any apparatus, means the undertaker to whom it belongs or by whom it is maintained.

3.  This Part of this Schedule does not apply to apparatus in respect of which the relations between Network Rail and the undertaker are regulated by the provisions of Part 3 of the 1991 Act.

4.  Regardless of any provision in this Order or anything shown on the land plans, Network Rail must not acquire any apparatus otherwise than by agreement.

5.—(1) If, in the exercise of the powers conferred by this Order, Network Rail acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of an undertaker to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the undertaker in question.

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, Network Rail requires the removal of any apparatus placed in that land, it must give to the undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order an undertaker reasonably needs to remove any of its apparatus) Network Rail must, subject to sub-paragraph (3), afford to the undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of Network Rail and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of Network Rail, or Network Rail is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the undertaker in question must, on receipt of a written notice to that effect from Network Rail, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of Network Rail under this Part of this Schedule is to be constructed in such manner and in such line or situation as may be agreed between the undertaker in question and Network Rail or in default of agreement settled by arbitration in accordance with article 34 (arbitration).

(5) The undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 34, and after the grant to the undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by Network Rail to be removed under the provisions of this Part of this Schedule.

(6) Regardless of anything in sub-paragraph (5), if Network Rail gives notice in writing to the undertaker in question that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of Network Rail, that work, instead of being executed by the undertaker, must be executed by Network Rail without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the undertaker.

(7) Nothing in sub-paragraph (6) authorises Network Rail to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

6.—(1) Where, in accordance with the provisions of this Part of this Schedule, Network Rail affords to an undertaker facilities and rights for the construction and maintenance in land of Network Rail of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between Network Rail and the undertaker in question or in default of agreement settled by arbitration in accordance with article 34 (arbitration).

(2) In settling those terms and conditions in respect of alternative apparatus to be constructed in or along any railway of Network Rail, the arbitrator must—

(a)give effect to all reasonable requirements of Network Rail for ensuring the safety and efficient operation of the railway and for securing any subsequent alterations or adaptations of the alternative apparatus which may be required to prevent interference with any proposed works of Network Rail or the traffic on the railway; and

(b)so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus constructed in or along the railway for which the alternative apparatus is to be substituted.

(3) If the facilities and rights to be afforded by Network Rail in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by Network Rail to that undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

7.—(1) Not less than 28 days before starting the execution of any works of the type referred to in paragraph 5(2) that are near to, or will or may affect, any apparatus the removal of which has not been required by Network Rail under paragraph 5(2), Network Rail must submit to the undertaker in question a plan, section and description of the works to be executed.

(2) Those works are to be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the undertaker is entitled to watch and inspect the execution of those works.

(3) Any requirements made by an undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If an undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by Network Rail, reasonably requires the removal of any apparatus and gives written notice to Network Rail of that requirement, paragraphs 1 to 6 apply as if the removal of the apparatus had been required by Network Rail under paragraph 5(2).

(5) Nothing in this paragraph precludes Network Rail from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) Network Rail is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

8.—(1) Subject to the following provisions of this paragraph, Network Rail must repay to an undertaker the reasonable expenses incurred by that undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus (including costs or compensation payable in connection with the acquisition of land for that purpose) which may be required in consequence of the execution of any such works as are referred to in paragraph 5(2).

(2) The value of any apparatus removed under the provisions of this Part of this Schedule is to be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by Network Rail or, in default of agreement, is not determined by arbitration in accordance with article 34 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to an undertaker in respect of works by virtue of sub-paragraph (1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

9.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraph 5(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of an undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any undertaker, Network Rail must—

(a)bear and pay the cost reasonably incurred by that undertaker in making good such damage or restoring the supply; and

(b)make reasonable compensation to that undertaker for any other expenses, loss, damages, penalty or costs incurred by the undertaker,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on Network Rail with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an undertaker, its officers, servants, contractors or agents.

(3) An undertaker must give Network Rail reasonable notice of any such claim or demand and no settlement or compromise may be made without the consent of Network Rail which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

10.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between Network Rail and an undertaker in respect of any apparatus laid or erected in land belonging to Network Rail on the date on which this Order is made.

PART 2FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

11.—(1) For the protection of any operator, the following provisions, unless otherwise agreed in writing between Network Rail and the operator, have effect.

(2) In this Part of this Schedule—

“the 2003 Act” means the Communications Act 2003(4);

“conduit system” has the same meaning as in the electronic communications code and references to providing a conduit system are to be construed in accordance with paragraph 1(3A) of that code;

“electronic communications apparatus” has the same meaning as in the electronic communications code;

“the electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act(4);

“electronic communications code network” means—

(a)

so much of an electronic communications network or conduit system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and

(b)

an electronic communications network which the Secretary of State is providing or proposing to provide;

“electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act; and

“operator” means the operator of an electronic communications code network.

12.  The exercise of the powers conferred by article 24 (statutory undertakers) is subject to paragraph 23 of Schedule 2 to the Telecommunications Act 1984(5) (undertaker’s works).

13.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or their construction, or of any subsidence resulting from any of those works—

(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works, or other property of an operator); or

(b)there is any interruption in the supply of the service provided by an operator, Network Rail must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and must—

(i)make reasonable compensation to an operator for loss sustained by it; and

(ii)indemnify an operator against claims, demands, proceedings, costs, damages and expenses which may be made or taken against, or recovered from, or incurred by, an operator by reason, or in consequence of, any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on Network Rail with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(3) The operator must give Network Rail reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand may be made without the consent of Network Rail which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between Network Rail and the operator under this paragraph is to be referred to and settled by arbitration under article 34 (arbitration).

14.  This Part of this Schedule does not apply to—

(a)any apparatus in respect of which the relations between Network Rail and an operator are regulated by the provisions of Part 3 of the 1991 Act; or

(b)any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development.

15.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between Network Rail and an operator in respect of any apparatus laid or erected in land belonging to Network Rail on the date on which this Order is made.

PART 3FOR THE PROTECTION OF THE ENVIRONMENT AGENCY

16.—(1) The following provisions apply for the protection of the Agency unless otherwise agreed in writing between Network Rail and the Agency.

(2) In this Part of this Schedule—

“the Agency” means the Environment Agency;

“construction” includes execution, placing, altering, replacing, relaying and removal and “construct” and “constructed” are construed accordingly;

“drainage work” means any watercourse and includes any land which provides or is expected to provide flood storage capacity for any watercourse and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage, flood defence or tidal monitoring and any ancillary works constructed as a consequence of works carried out for drainage purposes;

“the fishery” means any waters containing fish and fish in such waters and the spawn, habitat or food of such fish;

“plans” includes sections, drawings, specifications and method statements;

“specified work” means the temporary structure set out at (j) in Part 1 (authorised development) of Schedule 1 (authorised development and requirements) and so much of any work or operation authorised by this Order as is in, on, under, over or within 16 metres of a drainage work or is otherwise likely to—

(a)

affect any drainage work or the volumetric rate of flow of water in or flowing to or from any drainage work;

(b)

affect the flow, purity or quality of water in any watercourse or other surface waters or ground water;

(c)

cause obstruction to the free passage of fish or damage to any fishery; or

(d)

affect the conservation, distribution or use of water resources; and

“watercourse” includes all rivers, streams, ditches, drains, cuts, culverts, dykes, sluices, sewers and passages through which water flows except a public sewer.

17.—(1) Before beginning to construct any specified work, Network Rail must submit to the Agency plans of the specified work and such further particulars available to it as the Agency may within 28 days of the receipt of the plans reasonably require.

(2) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by the Agency, or determined under paragraph 27.

(3) Any approval of the Agency required under this paragraph—

(a)must not be unreasonably withheld or delayed;

(b)is deemed to have been given if it is neither given nor refused within 2 months of the submission of the plans or receipt of further particulars if such particulars have been required by the Agency for approval and, in the case of a refusal, accompanied by a statement of the grounds of refusal; and

(c)may be given subject to such reasonable requirements as the Agency may make for the protection of any drainage work or the fishery or for the protection of water resources, or for the prevention of flooding or pollution or in the discharge of its environmental duties.

(4) The Agency must use its reasonable endeavours to respond to the submission of any plans before the expiration of the period mentioned in sub-paragraph (3)(b).

18.  Without limitation on the scope of paragraph 17, but subject always to the provisions of that paragraph as to reasonableness, the requirements which the Agency may make under that paragraph include conditions requiring Network Rail at its own expense to construct such protective works, whether temporary or permanent, before or during the construction of the specified works (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary—

(a)to safeguard any drainage work against damage; or

(b)to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased,

by reason of any specified work.

19.—(1) Subject to sub-paragraph (2), any specified work, and all protective works required by the Agency under paragraph 18, must be constructed—

(a)without unnecessary delay in accordance with the plans approved or deemed to have been approved or settled under this Schedule; and

(b)to the reasonable satisfaction of the Agency,

and an officer of the Agency is entitled to watch and inspect the construction of such works.

(2) Network Rail must give to the Agency not less than 14 days’ notice in writing of its intention to commence construction of any specified work and notice in writing of its completion not later than 7 days after the date on which it is completed.

(3) If the Agency reasonably requires, Network Rail must construct all or part of the protective works so that they are in place prior to the construction of any specified work.

(4) If any part of a specified work or any protective work required by the Agency is constructed otherwise than in accordance with the requirements of this Part of this Schedule, the Agency may by notice in writing require Network Rail at Network Rail’s own expense to comply with the requirements of this Part of this Schedule or (if Network Rail so elects and the Agency in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as the Agency reasonably requires.

(5) Subject to sub-paragraph (6) and paragraph 23, if within a reasonable period, being not less than 28 days from the date when a notice under sub-paragraph (4) is served upon Network Rail, it has failed to begin taking steps to comply with the requirements of the notice and subsequently to make reasonably expeditious progress towards their implementation, the Agency may execute the works specified in the notice and any expenditure incurred by it in so doing is recoverable from Network Rail.

(6) In the event of any dispute as to whether sub-paragraph (4) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the Agency must not except in emergency exercise the powers conferred by sub-paragraph (5) until the dispute has been finally determined.

20.—(1) Subject to sub-paragraph (6) Network Rail must from the commencement of the construction of the specified works maintain in good repair and condition and free from obstruction any drainage work which is situated within the limits of deviation and on land held by Network Rail for the purposes of or in connection with the specified works, whether or not the drainage work is constructed under the powers conferred by this Order or is already in existence.

(2) If any such drainage work which Network Rail is liable to maintain is not maintained to the reasonable satisfaction of the Agency, the Agency may by notice in writing require Network Rail to repair and restore the work, or any part of such work, or (if Network Rail so elects and the Agency in writing consents, such consent not to be unreasonably withheld or delayed), to remove the work and restore the site to its former condition, to such extent and within such limits as the Agency reasonably requires.

(3) Subject to paragraph 23, if, within a reasonable period being not less than 28 days beginning with the date on which a notice in respect of any drainage work is served under sub-paragraph (2) on Network Rail, Network Rail has failed to begin taking steps to comply with the reasonable requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the Agency may do what is necessary for such compliance and may recover any expenditure reasonably incurred by it in so doing from Network Rail.

(4) If there is any failure by Network Rail to obtain consents or comply with conditions imposed by the Agency in accordance with this Part of this Schedule the Agency may serve written notice requiring Network Rail to cease all or any part of the specified works and Network Rail must cease the specified works or part of them until it has obtained the consent or complied with the condition unless the cessation of the specified works or part of them would cause greater damage than compliance with the written notice.

(5) In the event of any dispute as to the reasonableness of any requirement of a notice served under sub-paragraph (2) , the Agency must not except in a case of emergency exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined.

(6) This paragraph does not apply to—

(a)drainage works which are vested in the Agency, or which the Agency or another person is liable to maintain and is not prescribed by the powers of this Order from doing so; and

(b)any obstruction of a drainage work for the purpose of a work or operation authorised by this Order and carried out in accordance with the provisions of this Part of this Schedule.

21.  Subject to paragraph 23, if by reason of the construction of any specified work or of the failure of any such work the efficiency of any drainage work for flood defence purposes is impaired, or that drainage work is otherwise damaged, such impairment or damage must be made good by Network Rail to the reasonable satisfaction of the Agency and if Network Rail fails to do so, the Agency may make good the same and recover from Network Rail the expense reasonably incurred by it in so doing.

22.—(1) Network Rail must take all such measures as may be reasonably practicable to prevent any interruption of the free passage of fish in the fishery during the construction of any specified work.

(2) If by reason of—

(a)the construction of any specified work; or

(b)the failure of any such work,

damage to the fishery is caused, or the Agency has reason to expect that such damage may be caused, the Agency may serve notice on Network Rail requiring it to take such steps as may be reasonably practicable to make good the damage, or, as the case may be, to protect the fishery against such damage.

(3) Subject to paragraph 23, if within such time as may be reasonably practicable for that purpose after the receipt of written notice from the Agency of any damage or expected damage to a fishery, Network Rail fails to take such steps as are described in sub-paragraph (2), the Agency may take those steps and may recover from Network Rail the expense reasonably incurred by it in doing so.

(4) Subject to paragraph 23, in any case where immediate action by the Agency is reasonably required in order to secure that the risk of damage to the fishery is avoided or reduced, the Agency may take such steps as are reasonable for the purpose, and may recover from Network Rail the reasonable cost of so doing provided that notice specifying those steps is served on Network Rail as soon as reasonably practicable after the Agency has taken, or commenced to take, the steps specified in the notice

23.—(1) Nothing in paragraphs 19(5), 20(3), 21, 22(3) and (4) authorises the Agency to execute works on or affecting an operational railway forming part of Network Rail’s network without the prior consent in writing of Network Rail such consent not to be unreasonably withheld or delayed.

(2) Network Rail is deemed to have given its consent if it has not refused consent within 2 calendar months of receiving a written request by the Agency.

24.  Network Rail must indemnify the Agency in respect of all costs, charges and expenses which the Agency may reasonably incur or have to pay or which it may sustain—

(a)in the examination or approval of plans under this Part of this Schedule;

(b)in the inspection of the construction of the specified works or any protective works required by the Agency under this Part of this Schedule;

(c)in the carrying out of any surveys or tests by the Agency which are reasonably required in connection with the construction of the specified works.

25.—(1) Without affecting the other provisions of this Part of this Schedule, Network Rail must indemnify the Agency from all claims, demands, proceedings, costs, damages, expenses or loss, which may be made or taken against, recovered from, or incurred by, the Agency by reason of—

(a)any damage to any drainage work so as to impair its efficiency for the purposes of flood defence;

(b)any damage to the fishery;

(c)any raising or lowering of the water table in land adjoining the authorised development or any sewers, drains and watercourses;

(d)any flooding or increased flooding of any such lands; or

(e)inadequate water quality in any watercourse or other surface waters or in any groundwater,

which is caused by the construction of any of the specified works or any act or omission of Network Rail, its contractors, agents or employees whilst engaged upon the work.

(2) The Agency must give to Network Rail reasonable notice of any such claim or demand and no settlement or compromise may be made without the agreement of Network Rail which agreement must not be unreasonably withheld or delayed.

26.  The fact that any work or thing has been executed or done by Network Rail in accordance with a plan approved or deemed to be approved by the Agency, or to its satisfaction, or in accordance with any directions or award of an arbitrator, does not relieve Network Rail from any liability under the provisions of this Part of this Schedule.

27.  Any dispute arising between Network Rail and the Agency under this Part of this Schedule, if the parties agree, is to be determined by arbitration under article 34 (arbitration), but otherwise is to be determined by the Secretary of State for Environment, Food and Rural Affairs and the Secretary of State for Transport acting jointly on a reference to them by Network Rail or the Agency, after notice in writing by one to the other.

PART 4FOR THE PROTECTION OF HUTCHISON PORTS (UK) LIMITED AND THE FELIXSTOWE DOCK AND RAILWAY COMPANY

28.—(1) The following provisions apply for the protection of the Felixstowe operator, unless otherwise agreed in writing between Network Rail and the Felixstowe Dock and Railway Company.

(2) In this Part of this Schedule—

“access agreement” has the same meaning as section 83(1) (interpretation of Part 1) of the Railways Act 1993(6);

“the Felixstowe operator” means Hutchison Ports (UK) Limited and the Felixstowe Dock and Railway Company; and

“Network Code” means the common set of rules and industry procedures, regulated by the Office of Rail Regulation, that apply to all parties who have a contractual right of access to the network owned and operated by Network Rail as having effect from time to time, and includes any document (whatever called) that replaces the Network Code.

29.  At the same time as Network Rail consults persons with an access agreement in accordance with its obligations under Part D of the Network Code, Network Rail must consult the Felixstowe operator in writing about the timetable for Network Rail’s taking possession of the East Suffolk Line railway for the purposes of this Order.

30.  At the same time as Network Rail consults persons with an access agreement in accordance with its obligations under Part G of the Network Code, Network Rail must consult the Felixstowe operator in writing about any proposal by Network Rail that will impose a speed restriction on the East Suffolk Line between East Suffolk Junction and Westerfield Junction.

31.  As part of the consultation under paragraph 29 Network Rail must provide the Felixstowe operator with written particulars of the proposed timetable.

32.  As part of the consultation under paragraph 30 Network Rail must provide the Felixstowe operator with written particulars of the proposed speed restriction.

33.  Each consultation with the Felixstowe operator under paragraph 29 or paragraph 30 must specify the latest date by which the Felixstowe operator is required to respond.

34.  Network Rail must have regard to any response to the consultation from the Felixstowe operator which is received in writing on or before the date specified in accordance with paragraph 33, or such later date as may be agreed in writing between the parties.

35.  For the purposes of this Part of this Schedule any written document sent by Network Rail to the Felixstowe operator under this Part of this Schedule is duly sent to both Hutchison Ports (UK) Limited and the Felixstowe Dock and Railway Company if it is addressed to either or both those companies at the registered office of either of those companies or such other address as either company may have specified to Network Rail.

PART 5FOR THE PROTECTION OF NATIONAL HEALTH SERVICE BLOOD AND TRANSPLANT

36.—(1) The following provisions apply for the protection of NHSBT, unless otherwise agreed in writing between Network Rail and NHSBT.

(2) In this Part of this Schedule—

“NHSBT” means National Health Service Blood and Transplant acting in exercise of its statutory functions;

“NHSBT parking spaces” means 6 car parking spaces for the use of NHSBT during any period when, due to Network Rail’s exercise of the powers of this Order, NHSBT does not have the uninterrupted use of plot 58; and

“plot 58” means the land shown numbered 58 on the land plans.

(3) No works are to be commenced within plot 58 until—

(a)details of the provision for NHSBT parking spaces have been submitted to and approved by the relevant planning authority; and

(b)Network Rail has made the NHSBT parking spaces available to NHSBT in accordance with the approved details.

(4) Network Rail must continue to make the NHSBT parking spaces available to NHSBT for any period during which, due to Network Rail’s exercise of the powers of this Order, NHSBT does not have the uninterrupted use of plot 58.

(3)

1986 c. 44. A new section 7 was substituted by section 5 of the Gas Act 1995 (c. 45), and was further amended by section 76 of the Utilities Act 2000 (c. 27).

(4)

2003 c. 21. See section 106.

Back to top

Options/Help

Print Options

Close

Legislation is available in different versions:

Latest Available (revised):The latest available updated version of the legislation incorporating changes made by subsequent legislation and applied by our editorial team. Changes we have not yet applied to the text, can be found in the ‘Changes to Legislation’ area.

Original (As Enacted or Made): The original version of the legislation as it stood when it was enacted or made. No changes have been applied to the text.

Close

Opening Options

Different options to open legislation in order to view more content on screen at once

Close

More Resources

Access essential accompanying documents and information for this legislation item from this tab. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as enacted version that was used for the print copy
  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • correction slips
  • links to related legislation and further information resources
Close

More Resources

Use this menu to access essential accompanying documents and information for this legislation item. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as made version that was used for the print copy
  • correction slips

Click 'View More' or select 'More Resources' tab for additional information including:

  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • links to related legislation and further information resources