The Cleve Hill Solar Park Order 2020

PART 6 U.K.FOR THE PROTECTION OF UKPN

1.  For the protection of UKPN as referred to in this part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and UKPN.U.K.

2.  In this part of this Schedule—U.K.

“alternative apparatus” means alternative apparatus adequate to enable UKPN to fulfil its statutory functions in a manner not less efficient than previously;

“apparatus” means electric lines or electrical plant (as defined in the 1989 Act), belonging to or maintained by UKPN;

“functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

“UKPN” means South Eastern Power Networks plc (Company No. 03043097) whose registered office is at Newington House, 237 Southwark Bridge Road, London SE1 6NP;

3.  This part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and UKPN are regulated by the provisions of Part 3 of the 1991 Act.U.K.

4.  Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 10 (temporary stopping up of streets), UKPN is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.U.K.

5.  Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.U.K.

6.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that UKPN's apparatus is relocated or diverted, that apparatus must not be removed under this part of this Schedule, and any right of UKPN to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of UKPN in accordance with sub–paragraphs to .U.K.

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to UKPN written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order UKPN reasonably needs to remove any of its apparatus) the undertaker must, subject to sub–paragraph , afford to UKPN the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub–paragraph , in the land in which the alternative apparatus or part of such apparatus is to be constructed, UKPN must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed provided that this obligation shall not require UKPN to exercise any power it may have to acquire any land or rights by compulsory purchase order.

(4) Any alternative apparatus to be constructed in land of the undertaker under this part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between UKPN and the undertaker or in default of agreement settled by arbitration in accordance with article 35 (arbitration).

(5) UKPN must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 35 (arbitration), and after the grant to UKPN of any such facilities and rights as are referred to in sub-paragraph or , proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this part of this Schedule.

(6) Regardless of anything in sub–paragraph , if the undertaker gives notice in writing to UKPN that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by UKPN, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of UKPN.

(7) Nothing in sub–paragraph authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

7.—(1) Where, in accordance with the provisions of this part of this Schedule, the undertaker affords to UKPN facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and UKPN or in default of agreement settled by arbitration in accordance with article 35 (arbitration).U.K.

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to UKPN than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to UKPN as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

8.—(1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph , the undertaker must submit to UKPN a plan, section and description of the works to be executed.U.K.

(2) Those works must be executed only in accordance with the plan, section and description submitted under sub–paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub–paragraph by UKPN for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and UKPN is entitled to watch and inspect the execution of those works.

(3) Any requirements made by UKPN under sub–paragraph must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If UKPN in accordance with sub–paragraph and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs and apply as if the removal of the apparatus had been required by the undertaker under paragraph .

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) The undertaker is not required to comply with sub–paragraph (1) in a case of emergency but in that case it must give to UKPN notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub–paragraph in so far as is reasonably practicable in the circumstances.

9.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to UKPN the reasonable expenses incurred by UKPN in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 6(2).U.K.

(2) There is to be deducted from any sum payable under sub–paragraph (1) the value of any apparatus removed under the provisions of this part of this Schedule, that value being calculated after removal.

(3) If in accordance with the provisions of this part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 35 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to UKPN by virtue of sub–paragraph (1) is to be reduced by the amount of that excess.

(4) For the purposes of sub–paragraph —

(a)an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 6(2); and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to UKPN in respect of works by virtue of sub–paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on UKPN any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

10.—(1) Subject to sub–paragraphs and , if by reason or in consequence of the construction of any of the works referred to in paragraph , any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of UKPN, or there is any interruption in any service provided, or in the supply of any goods, by UKPN, the undertaker must—U.K.

(a)bear and pay the cost reasonably incurred by UKPN in making good such damage or restoring the supply; and

(b)indemnify UKPN for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from UKPN,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub–paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of UKPN, its officers, servants, contractors or agents.

(3) UKPN must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

11.  Nothing in this part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and UKPN in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.U.K.

12.  Any difference under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and UKPN, be determined by arbitration in accordance with article 35 (arbitration).U.K.